A87-610 Kamehameha Schools 2021 Motion to Amend
BACKGROUND
The current motion is for Modification, Time Extension, and Release and Modification of Conditions under the 2014 Decision and Order (“2014 Order”).
Summary of Petition – Common name of project (may be/probably different than the Petitioner Name)
To Amend the Agricultural Land Use District Boundary into the Urban Land Use District for Approximately 1,395 Acres at Waiawa, ‘Ewa, O‘ahu, State of Hawai‘i, Tax Map Key Nos.: 9-4-06: Portion of 26; 9-6-04: Portion of 1 and Portion of 16; and 9-6-05: Portion of 1, Portion of 7 and Portion of 14.
DOCKET STATUS
Petitioner has filed the current Motion to Amend (“2021 Motion”) on December 10, 2021. Staff is currently reviewing the filing and tentatively scheduled to be considered in April 2022. Please check the LUC Calendar for updates.
Agenda & Minutes:
November 20 & 21, 2019: Agenda | Minutes 11/20/19 | Minutes 11/21/19
January 08-09, 2020: Agenda | Minutes
March 23, 2022: Agenda | Minutes | YouTube
April 14, 2022: Agenda | Minutes | YouTube
Petitioner’s Filings on 12/10/21
- Motion for Modification, Time Extension, and Release and Modification of Conditions,
- COS
- Memorandum in Support of Motion
- Affidavit of Kamuela Cobb-Adams
- Affidavit of Derek B. Simon
- Exhibits 1-4
- Exhibits 5-8
- Exhibits 9-12, Appendices A, B, C
Letter in Support of Time Extension (12/20/21)
Petitioner’s 2021 Annual Report for County Ordinance 98-01 (01/19/22)
Notice of Appearance from Co-Counsel Jennifer Lim, Esq. (01/20/22)
Petitioner’s Filings on 02/25/22
- Stipulated Proposed Conditions of Approval
- KS First List of Witnesses
- KS First List of Exhibits and Declaration of Derek B. Simon
- COS
- Exhibit 13 Updated Conceptual Site Plan
- Exhibit 14 Part 1, Part 2, Part 3, Part 4 Archaeological Inventory Survey (2015)
- Exhibit 15 City & County of Honolulu, DPP Letter dated April 29, 2014
- Exhibit 16 Resume of Nicholas J. Molinari
- Exhibit 17 Resume of Lisa S. Kettley
- Exhibit 18 Resume of Jason Alapaki Jeremiah
- Exhibit 19 Resume of Christopher M. Monahan
- Exhibit 20 Resume of Shane Peters
- Exhibit 21 Resume of Sohrab Rashid
- Exhibit 22 Resume of Sam Ley
- Exhibit 23 Resume of Paul T. Matsuda
- Exhibit 24 Resume of Maya Lani LeGrande
- Exhibit 25 Resume of Thomas Snetsinger
- Exhibit 26 Written Direct – Dana N. Sato
- Exhibit 27 Written Direct – Nicholas Molinari
- Exhibit 28 Written Direct – Lisa Kettley
- Exhibit 29 Written Direct – Jason Jeremiah
- Exhibit 30 Written Direct – Christopher Monahan
- Exhibit 31 Written Direct – Sohrab Rashid
- Exhibit 32 Community Outreach Report dated October 15, 2021
- Exhibit 33 Supplemental Community Outreach Report dated February 22, 2022
- Exhibit 34 Petitioner’s Proposed Order Granting Motion for Modification, Time Extension and Release and Modification of Conditions
- Exhibit 35 Letter Memo – Completion of Installation/Marking Temporary Preservation Buffer dated November 15, 2021
- Exhibit 36 Excerpt from Table 21-3 (Master Use Table), Chapter 21 Revised Ordinances of Honolulu
- Exhibit 37 Waiawa Master Plan Exhibit 1 (Waiawa Master Planning Area and Potential State Land Use Districts Boundary Amendment Area) dated October 4, 2019
- Exhibit 38 Waiawa Master Plan Exhibit 3 (Conceptual Land Use Plan Phase A and B (TOD Increment) w/ Solar) dated October 4, 2019
- Exhibit 39 2021 Kamehameha Schools Annual Report
- Exhibit 40 Stipulated Proposed Conditions of Approval, dated and filed February 25, 2022
- Exhibit 41 Preliminary Civil Engineering Considerations (Group 70) dated August 2021
Petitioner’s Filings on 04/07/22
- KS Second List of Witnesses
- KS Second List of Exhibits & COS
- Exhibit 42 KS Revised Master Plan and Schedule for Development with Exhibits 1-3, dated October 7, 2019
- Exhibit 43 Waiawa, A Community for a Better Tomorrow, Land Use Commission Update (PowerPoint), dated January 9, 2020
- Exhibit 44 Honolulu Star-Advertiser article (“Waiawa landowner seeks to expand plans; A Kamehameha Schools project looks to develop 11,000 homes and cost $4B”), dated January 10, 2020
- Exhibit 45 Honolulu Star-Advertiser editorial (“Waiawa hopes high for housing, energy”) dated January 15, 2020
- Exhibit 46 Master Plan Gantt Chart, updated April 7, 2022
- Exhibit 47 Synergy Between Solar & Master Plan Development at Waiawa (PowerPoint), April 2022
- KS Amended COS for Second List of Exhibits (4/8/22)
Petitioner’s Filing on 05/02/22
- Supplemental Memorandum in Support of Dec. 10, 2021 Motion
- KS Third List of Exhibits,
- Declaration of Derek B. Simon and COS
- Exhibit 48 FOF, COL and D&O
- Exhibit 49 Order Granting Motion to Amend Condition No. 6
- Exhibit 50 ACT 51
- Exhibit 51 ACT 187
- Exhibit 52 SCRep. 803-72 Economic Development on H.B. No. 2249-72
- Exhibit 53 Central O’ahu Sustainable Communities Plan
- Exhibit 54 Site Aerial Photos
- Exhibit 55
- Exhibit 56 Final Proposed HAR Title 11 Department of Health Chapter 200.1 Environmental Impact Statement Rules
- Exhibit 57 Timelines of Certain Environmental Assessments and Environmental Impact Statements
Second Stipulated Proposed Conditions of Approval (5/24/2022)
Petitioner’s Filing of Notice of Imposition of Conditions by the Land Use Commission (7/7/2022)
Petitioner’s Filing of Declaration of Conditions Imposed by the State Land Use Commission (8/25/22)
County’s Request for Extension of Time to Respond to Petitioner’s Motion (12/22/21)
County’s Response to Petitioner’s Motion for Modification, Time Extension and Mod of Conditions (02/10/22)
DPP’s Notice of Appearance of Counsel (04/12/22)
County’s Proposed Revisions to Conditions 10 & 11 (05/17/22)
Petitioner’s Letter to LUC referring to scheduling (01/20/22)
DOT re AES Waiawa Phase 2 Solar Project (05/11/23)
Christopher Delaunay- Pacific Resource Partnership
Josh Meyers- Moss Hawaii Energy
Pane Meatoga III- Hawaii Operating Engineers Industry Stabilization
Nathaniel Kinney- Hawaii Regional Council of Carpenters
Stanford Carr – Stanford Carr Development, LLC
Garret Matsunami- Castle & Cooke Hawai’i